X
28Jan

Contract Clause for Weather Delays Does Not Override Suspension of Work Clause

In the recent case of Granite Construction Co., ASBCA 62281, the Armed Services Board of Contract Appeals granted partial summary judgment to a contractor that sought delay damages under FAR 52.242-14, Suspension of Work—overcoming the Government's argument that the delays were contemplated under a separate clause for adverse weather delays....
By: Davis Wright Tremaine LLP
Source Url: https://www.jdsupra.com/legalnews/contract-clause-for-weather-delays-does-4855083/

Related

IRS Misclassifications and Costly Penalties: Independent Contractor or Employee?

Failing to properly classify an individual as an independent contractor can result in expensive pena...

Read More >

WHD Issues Its First Opinion Letters of the. . . Decade

Seyfarth Synopsis: The U.S. Department of Labor’s Wage & Hour Division recently issued two opinion ...

Read More >

OFCCP Grants Exemption And Waiver For New Coronavirus Relief Contracts

In a Memorandum issued this week, OFCCP has granted a three-month, national interest exemption and w...

Read More >

Fifth Circuit Rules Individual Mandate Unconstitutional; Fate of Rest of ACA Remains in Doubt

In a 2-1 decision, the Fifth Circuit Court of Appeals has upheld a district court ruling that the in...

Read More >

Jury Shocker: 93 Million Reasons Why The ILWU May Soon Cease To Exist

A recent $93.6 million verdict from an Oregon jury has the potential to bankrupt a union that some d...

Read More >

DOJ Antitrust Division Issues New Manual on Merger Guidelines

On September 3, 2020, the U.S. Department of Justice’s (DOJ) Antitrust Division (the Division) publ...

Read More >