X
15Jan

ASBCA Holds that Anticipated Days of Adverse Weather Do Not Decrease Delay Damages

Many construction contractors working with the United States Army Corps of Engineers (USACE) have seen it happen: they experience a government-caused delay or suspension, which USACE agrees to pay for, but then USACE deducts the anticipated adverse weather days stated in the contract for the delay period from the compensable time extension. That may no longer be a defensible practice after the ASBCA’s recent decision in the Appeal of Granite Construction Company....
By: Obermayer Rebmann Maxwell & Hippel LLP
Source Url: https://www.jdsupra.com/legalnews/asbca-holds-that-anticipated-days-of-1110814/

Related

Structuring PPM and DPM Transactions for Maximum Success: Tackling Front-End Issues

In order to structure physician practice management (“PPM”) and dental practice management (“DPM”...

Read More >

The Coronavirus Heat-Seeking Missile

The new coronavirus is a heat-seeking missile headed straight for our health care system. The virus ...

Read More >

Federal Communications Commission Penalizes Marriott Vacations for Unauthorized Transfer of Private Radio Licenses

Because many hotels and resorts hold Federal Communications Commission (“FCC”) licenses for the wi...

Read More >

Paid Family Medical Leave Amendments and Draft Rules Highlight Supplemental Benefit Options for Employers

In April 2019, Governor Jay Inslee signed SHB 1399, which amended the Washington Paid Family Medical...

Read More >

Final Rule from U.S. Department of Labor Provides Clarifying Update to Joint Employer Regulations

The U.S. Department of Labor recently issued a Final Rule to update longstanding "joint employer" re...

Read More >

Third Circuit Upholds Anti-Assignment Provision Barring Provider’s ERISA Suit Against Insurer

The US Court of Appeals for the Third Circuit recently confirmed that “anti-assignment” provisions...

Read More >