07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
In late July, the Committee on Foreign Investment in the United States (CFIUS) released its Annual R...
Read More >
When one party to an M&A agreement alleges that the other breached its representations and warrantie...
Read More >
Significant Changes to Employment Act, Effective April 1, 2019 - New Legislation Enacted - Signifi...
Read More >
In 2016, Florida voters soundly passed Amendment 2, Florida’s medical marijuana law, with over 71% ...
Read More >
The U.S. Department of Labor recently announced proposed regulations on overtime that would render m...
Read More >
One of the essential factors for plaintiffs in discrimination cases can be showing that they were tr...
Read More >