X
07Aug

ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction

In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By: Obermayer Rebmann Maxwell & Hippel LLP
Source Url: https://www.jdsupra.com/legalnews/asbca-holds-the-government-to-account-91537/

Related

Leveraged Acquisitions Roundtable

Drinker Biddle’s Corporate and Securities Group recently hosted its 13th annual roundtable discussi...

Read More >

New Department of Labor Rule Expands Overtime Eligibility

On September 24, 2019, the Department of Labor announced its final rule updating the salary threshol...

Read More >

California Supreme Court Limits Recovery for PAGA Claims

Are you familiar with PAGA? Do you have a PAGA claim for unpaid wages filed against you right now? I...

Read More >

Law Firm Mergers: A Primer Based on 30 Recent Merger Discussions

In our recent analysis on The Legal Marketplace in a Post-COVID World, we predicted a significant up...

Read More >

PEOs, Staffing Companies: Watch Proposed New Joint Employer Rule

Professional Employer Organizations, franchisors, business advisors, and staffing agencies should ta...

Read More >