07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
On November 17, 2020, the U.S. Internal Revenue Service (“IRS”) posted new FAQs providing that an ...
Read More >
Buyers in M&A deals often contend that they value a target company based on the seller’s representa...
Read More >
In early August, to much fanfare and the promise of "radical reform", the government published the "...
Read More >
Seyfarth Synopsis: The Second Circuit has affirmed summary judgment for the employer, Aetna, in an e...
Read More >
If people pass on enough incorrect information out there, you start to believe it. When I worked at ...
Read More >
First off you always need to be prepared for the worst. This means you have protection to care for y...
Read More >