07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
On July 22, 2019, DOL’s Wage and Hour Division issued an opinion letter (FLSA2019-10) on whether an...
Read More >
Owners and contractors trying to understand the full impact of COVID-19 on their projects are likely...
Read More >
Seyfarth Synopsis: Following Delaware’s lead in Trulia, an Illinois District Court judge refused to...
Read More >
In a departure from the federal Americans with Disabilities Act (ADA) and other state anti-discrimin...
Read More >
Below is a summary of the main developments in US and EU corporate governance and securities law and...
Read More >
The Colorado Court of Appeals announced a recent published opinion in which, although the Court cons...
Read More >