07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
This blog post is about walls and fences (but probably not the ones you may be thinking about). The ...
Read More >
Due to a flood of requests, the Ohio Bureau of Workers’ Compensation (BWC) Board of Directors reque...
Read More >
Hosts Tom Fox and Mike Volkov launch their new podcast series by talking about their favorite Marx B...
Read More >
Comprehensive FAQs For Employers On The COVID-19 Coronavirus - Fisher Phillips has assembled a cro...
Read More >
Non-ERISA 403(b) plans are the last stand for poorly run, highly expensive retirement plans. It is s...
Read More >
It's difficult enough to keep on top of the news at the moment – not to mention the raft of recent ...
Read More >