07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
Last summer, the U.S. Supreme Court issued a historic ruling that benefits employers faced with the ...
Read More >
The Small Business Administration (SBA) has designated COVID-19 as a qualifying event for the provis...
Read More >
In This Issue. The Securities and Exchange Commission (SEC) adopted a rule permitting most exchange-...
Read More >
Frazier Healthcare Partners has announced it has acquired EPTAM Precision Solutions. EPTAM, with lo...
Read More >
The DE OFCCP Week in Review (WIR) is a simple, fast and direct summary of relevant happenings in the...
Read More >
On March 29, 2019, Mexico’s government launched the Pilot Program to Register Domestic Workers to t...
Read More >