07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
The social media revolution has changed the modern workplace in ways that could not possibly have be...
Read More >
The Ballard Spahr Zoning and Land Use Team is continuing to monitor all aspects of the Philadelphia ...
Read More >
On September 23, 2019, the U.S. Department of the Treasury and the Internal Revenue Service (IRS) pu...
Read More >
The New York state legislature has passed a bill that would allow employees making certain claims fo...
Read More >
If 2018 was a year of elevator music at the National Labor Relations Board, 2019 was symphony of sou...
Read More >
A federal district court in North Carolina enforced a forum selection clause in a short-term disabil...
Read More >