07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Source Url: https://www.jdsupra.com/legalnews/asbca-holds-the-government-to-account-91537/
Related
Senate Bill 1784, which passed both houses of the General Assembly and currently is awaiting the Gov...
Read More >
Proposed revisions to current financial statement disclosure requirements for business acquisitions ...
Read More >
In today’s highly competitive healthcare environment, investors may find themselves in an auction p...
Read More >
Medical Center-Managing Companies Fired Market Sales Manager Following Cancer Diagnosis, Federal Age...
Read More >
As mentioned in a prior update, Governor Wolf is now permitting residential and commercial construct...
Read More >
Seyfarth synopsis: The Supreme Court has just granted certiorari in a case regarding the question of...
Read More >