07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
Google cut costs by rescinding offers to more than 2,000 contract workers due to the strains of the ...
Read More >
On September 26, 2019, California’s Second District Court of Appeals in Gustavo Naranjo, et al. v. ...
Read More >
Now that the 2018 EEO-1 Component 1 filing deadline has passed, employers have been anxiously awaiti...
Read More >
The term “joint employer” is often one of grave concern to employers. When, for example, Company A...
Read More >
Seyfarth Synopsis: As we prepare to enter 2020, employers with a presence in Massachusetts should be...
Read More >
In a December 16, 2019 decision, the National Labor Relations Board (Board) held that employers’ st...
Read More >