07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
Retail Giant Refused to Allow Job Applicant to Take Pre-Hiring Physical Assessment Test Due to Obvi...
Read More >
New York is on the precipice of passing a law that would allow employees to easily file liens agains...
Read More >
2020 has been one of the most eventful and unprecedented years for competition law in Thailand. This...
Read More >
Imagine, an employee in your organization advises that they need to take leave pursuant to the Famil...
Read More >
On October 31, 2019, the California Department of Justice (“DOJ”) issued a denial letter rejecting...
Read More >
News of an outbreak of a new coronavirus first identified in Wuhan, Hubei Province, China raises iss...
Read More >