07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Source Url: https://www.jdsupra.com/legalnews/asbca-holds-the-government-to-account-91537/
Related
The unprecedented health crisis arising from the novel Coronavirus disease (“COVID-19”) and measur...
Read More >
Although “construction” was originally deemed by Governor Cuomo to be “essential”, and thus exem...
Read More >
School is back in session and employees may soon be asking for time off to attend school related act...
Read More >
Employee Was Unlawfully Harassed by Manager, Then Fired After He Complained, Federal Agency Charged ...
Read More >
On November 27, 2019, the Internal Revenue Service, U.S. Department of Labor, and U.S. Department of...
Read More >
Late last year, we wrote about Shore v. The Charlotte-Mecklenburg Hospital Authority, et al., in whi...
Read More >