07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
The global health crisis brought on by the spread of the Novel Coronavirus (“COVID-19”) continues ...
Read More >
The long seller’s market may be over, which is welcome news for many companies that are eager and a...
Read More >
Supreme Court Declines to Weigh In on Website Accessibility - In a closely watched case that many h...
Read More >
Just before the Labor Day holiday, the Mine Safety and Health Administration published a long-expect...
Read More >
This client alert analyses the primary Employer risks, arising out of the construction of major hydr...
Read More >
With another busy year for employment law legislation throughout New York State and New York City co...
Read More >