07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
The Fourth Circuit’s recent decision in Evangeline Parker v. Reema Consulting Services, Incorporate...
Read More >
Welcome to this special five-part podcast series with Jay Rosen, VP of Business Development for Affi...
Read More >
In a year marked by unexpected challenges and rapid change, staying connected with industry peers an...
Read More >
Senior Living Center Refused Employee's Request for an Accommodation, Resulting in Her Termination, ...
Read More >
While the economy continues to enjoy steady growth, financial experts warn that an economic slowdown...
Read More >
New Tripartite Advisory on Provision of Rest Areas for Outsourced Workers - New Regulation or Offic...
Read More >