07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
Drinker Biddle’s Corporate and Securities Group recently hosted its 13th annual roundtable discussi...
Read More >
On September 24, 2019, the Department of Labor announced its final rule updating the salary threshol...
Read More >
Are you familiar with PAGA? Do you have a PAGA claim for unpaid wages filed against you right now? I...
Read More >
In our recent analysis on The Legal Marketplace in a Post-COVID World, we predicted a significant up...
Read More >
Organized labor wasted no time in securing Governor Pritzker’s signature on legislation that undoub...
Read More >
Professional Employer Organizations, franchisors, business advisors, and staffing agencies should ta...
Read More >