07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
On May 3, 2019, the SEC issued a proposed rule that would amend the financial statement requirements...
Read More >
In a move certain to bring employers some holiday cheer, the NLRB has announced changes to its rules...
Read More >
As I have discussed previously on Dickinson Wright’s All Things HR Blog, the Department of Labor’s...
Read More >
Effective February 13, 2020, foreign investment in U.S. businesses and real estate will require pre-...
Read More >
As businesses throughout the State of California continue to grapple with the potential implications...
Read More >
A New Zealand advertising agency employee recently made headlines after bringing an emotional suppor...
Read More >