07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
On September 24, 2019, the United States Department of Labor (“DOL”) released the long-awaited rev...
Read More >
If you want to avoid potential liability from a former employee, remember a key maxim: Stick to your...
Read More >
Historically, the sale of a private company carried with it a significant risk of claims by the purc...
Read More >
On January 9, 2020, the U.S. Senate confirmed by voice vote both of President Donald Trump’s nomine...
Read More >
Minnesota Governor Tim Walz's Executive Order 20-20 requesting Minnesotans to limit movements outsid...
Read More >
In this special bonus podcast, I am joined by Jay Rosen to discuss the stunning resolution to one of...
Read More >