07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
A federal court in California has prevented, at least for now, an expansive anti-arbitration law fro...
Read More >
We’ve noted before that AB 51 – the California legislature’s latest attempt to attack workplace a...
Read More >
This Lawflash provides multinational companies with operations in the People’s Republic of China (P...
Read More >
On July 30, 2019, a lawsuit was filed in the U.S. District Court for the Eastern District of Texas s...
Read More >
The “20% Rule,” which provided guidance to employers for when they must pay tipped employees minim...
Read More >
Due to protests, the City of Philadelphia is currently shut down. Philadelphia Zoning, Land Use, an...
Read More >