07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
Employers are rightfully concerned about what, if anything, they should be doing to respond to the c...
Read More >
Recently Mexico has been facing a considerable and seemingly uncontrollable increase in femicide cas...
Read More >
I’ve represented clients on both sides of freeze-out mergers of privately owned business entities, ...
Read More >
In the Memorandum Opinion, Fortis Advisors LLC v. Shire US Holdings, Inc., No. 2018-0933-JRS (Del. C...
Read More >
In one of its first major rulings, Hong Kong's Competition Tribunal (the "Tribunal") has ruled again...
Read More >
City Council approved the Chicago Fair Workweek Ordinance by unanimous vote on July 24, 2019. This p...
Read More >