07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
The patchwork of paid leave laws around the country is getting increasingly more intricate as local ...
Read More >
Title VII, which prohibits employment discrimination on the basis of race, color, religion, sex, and...
Read More >
On 10 January 2020, in response to missile attacks by the Iranian military targeting two U.S. bases ...
Read More >
When I was a kid, there were advertising campaigns that advised people to check their blood pressure...
Read More >
Global Protein Prods., Inc. v. Le, 42 Cal. App. 5th 352 (2019) - Global Protein Products, Inc. (“...
Read More >
Report on Supply Chain Compliance 2, no. 21 (November 7, 2019) - The deadline for compliance with a...
Read More >