07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
On January 14, 2020, the House Committee on Education and Labor voted to advance the Pregnant Worker...
Read More >
In July, we reported that the New York State Legislature had passed a bill that could substantially ...
Read More >
2 December - The Financial Conduct Authority ("FCA") updated the following webpages: - webpage o...
Read More >
The novel coronavirus (COVID-19) pandemic has caused significant volatility in stock prices, resulti...
Read More >
Trucking companies will no longer need to pay their drivers for certain off-duty time, potentially i...
Read More >
Gig workers in New York City recently gained a suite of workplace protections normally reserved for ...
Read More >