X
07Aug

ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction

In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By: Obermayer Rebmann Maxwell & Hippel LLP
Source Url: https://www.jdsupra.com/legalnews/asbca-holds-the-government-to-account-91537/

Related

Managing Contractual Performance in Times of Sanitary Crisis: The Spanish Law Perspective

The unprecedented health crisis arising from the novel Coronavirus disease (“COVID-19”) and measur...

Read More >

No-Damages-for-Delay Clauses and the COVID-19 Crisis

Although “construction” was originally deemed by Governor Cuomo to be “essential”, and thus exem...

Read More >

School’s In, May Mean Recess For Parents (And Grandparents): California Provides For School Leave

School is back in session and employees may soon be asking for time off to attend school related act...

Read More >

Belle Tire Distributors to Pay $55,000 to Settle EEOC Racial Harassment and Retaliation Lawsuit

Employee Was Unlawfully Harassed by Manager, Then Fired After He Complained, Federal Agency Charged ...

Read More >

Proposed Regulations Mandate New Price and Cost-Sharing Disclosures for Group Health Plans

On November 27, 2019, the Internal Revenue Service, U.S. Department of Labor, and U.S. Department of...

Read More >

ERISA-Exempt Governmental Plan Withstands Putative Class Action Challenge

Late last year, we wrote about Shore v. The Charlotte-Mecklenburg Hospital Authority, et al., in whi...

Read More >