07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
On 26 July 2019, the Greek Supervisory Authority (SA) found Pricewaterhouse Coopers (“PwC”) not co...
Read More >
The Tax Cuts and Jobs Act of 2017 created a lucrative new tax incentive for certain business owners:...
Read More >
The next session of the Supreme Court of the United States (SCOTUS) is just around the corner. On Oc...
Read More >
Today social media platforms, including Facebook and LinkedIn, allow employers to target their job l...
Read More >
On June 18, 2019, Connecticut Governor Ned Lamont signed into law Public Act 19-16, “An Act Combatt...
Read More >
On the same day as the departure of the lone Democratic Board member, the National Labor Relations B...
Read More >