07Aug
ASBCA Holds the Government to Account for Changes to the Design Process that Delayed Construction
In an important case for architects and design-builders, the Armed Services Board of Contract Appeals (ASBCA) held that the United States Army Corps of Engineers (USACE) is liable for delays arising from design-reviewer comments that change the design process specified in the contract. Many architects and design-builders have seen it happen: they submit a design submittal in accordance with the requirements of the contract, only to have a Government design-reviewer cause a delay by demanding...
By:
Obermayer Rebmann Maxwell & Hippel LLP
Related
Today, the SEC published in the Federal Register a proposed notice of an exemptive order (the “Prop...
Read More >
The US Department of Justice and the Federal Trade Commission recently issued an updated set of guid...
Read More >
J&F Investmentos SA (“J&F), a Brazilian private investment company, plead guilty to FCPA bribery vi...
Read More >
The second of three packages of proposed 2020 amendments to the German rules on control over foreign...
Read More >
Following the success of our three-part webinar series produced together with Houlihan Lokey in Spri...
Read More >
The district court in Chamber of Commerce of the United States, et al. v. Becerra, et al., E.D. Cal....
Read More >