X
05Dec

Government Held Accountable for Delays to Fast Track Design Process

The Armed Services Board of Contract Appeals (the “Board”) recently held the government liable for design delays where the government prematurely required details in design submissions and failed to provide comments on design submissions within the 14-day period allotted for government comments in the contract......
By: Bradley Arant Boult Cummings LLP
Source Url: https://www.jdsupra.com/legalnews/government-held-accountable-for-delays-43441/

Related

Illinois Outlaws Questions About Job Applicants’ Prior Salaries

Beginning September 29, 2019, it will be against the law in Illinois for employers to ask job applic...

Read More >

HR Quick Takes: Limiting Overtime

Q: An hourly employee has hit 40 hours at noon on Friday, can I send them home to avoid overtime? A...

Read More >

California Subcontractor Gets a Kick in the Rear (or Perhaps the Front) for Prematurely Recording Mechanics Lien

California provides three statutorily recognized construction payment remedies: (1) mechanics liens;...

Read More >

Connecticut Enacts Sweeping Legislation Addressing Workplace Harassment

Joining the ranks of New York and California, Connecticut has adopted legislation that significantly...

Read More >

How Might Virginia’s New Legislative Trifecta Affect Employers in the Commonwealth in 2020?

In the November 2019 election Virginia gained a Democratic “trifecta”—both legislative chambers a...

Read More >

New CFIUS Regulations Foreshadow an Increased Impact on the Insurance Industry

On September 24, 2019, the U.S. Department of the Treasury (“Treasury”) proposed regulations to ex...

Read More >